Capitol Visitor Center:

Update on Status of Project's Schedule and Cost as of April 27, 2006

GAO-06-665T: Published: Apr 27, 2006. Publicly Released: Apr 27, 2006.

Additional Materials:


Terrell G. Dorn
(202) 512-3000


Office of Public Affairs
(202) 512-4800

This testimony focuses on the Architect of the Capitol's progress in achieving selected project milestones and in managing the project's schedule since Congress's March 15, 2006, hearing on the project. As part of this discussion, we will address a number of key challenges and risks that continue to face the project, as well as actions AOC has taken or plans to take to address these risks. In addition, we will discuss the status of the project's costs and funding.

Since Congress's March 15 CVC hearing, the CVC team has continued to move the project's construction forward, and AOC is still proposing the same opening dates--April 2007 for the base CVC project and May 2007 for the House and Senate expansion spaces--but we continue to believe, as we said at the March hearing, that the proposed opening dates do not allow enough time to complete several critical activities and to address problems, challenges, risks, and uncertainties. Since the March 15 hearing, the installation of critical interior wall and floor stone has continued, together with other interior and exterior construction work, and the sequence 2 contractor has further developed plans to prevent trade stacking during finish work. However, the pace of interior wall and floor stone installation remained below the targeted pace; the dates for completing the construction of the overall base project and expansion spaces were extended; and several activities fell behind schedule--not enough to affect the overall completion dates yet, but increasing the potential for future delays. In addition, the sequence 2 contractor met only 1 of the 13 milestones being tracked for this hearing, and this contractor's monthly billings indicate that construction work is not likely to be completed on schedule as AOC anticipated. The CVC's fire protection system has not yet been approved; critical building systems still have to be commissioned and tested; and although the project's overall design is essentially complete, certain design or work scope elements are still incomplete or are being clarified or refined. If the CVC team is successful in addressing these issues, we believe that the base CVC project can still possibly be opened to the public with a temporary cap on visitor occupancy in May 2007 and that the expansion spaces can likely be opened for occupancy beginning in mid-August to early September 2007. AOC may be able to reduce some of the time scheduled for the expansion spaces if it implements a phased opening plan and is able to perform acceptance testing of the CVC and the expansion spaces concurrently rather than sequentially--possibilities AOC is continuing to explore. However, the delays that have occurred since Congress's last CVC hearing compound the concern we previously expressed that AOC will be challenged to meet even the later dates we are projecting because of the problems, challenges, risks, and uncertainties facing the project. Accordingly, we plan to reassess the project's schedule again this summer. As we reported at Congress's March 15 CVC hearing, we estimate that the total cost to complete the entire CVC project is about $556 million without an allowance for risks and uncertainties and $584 million with such an allowance. To date, about $530 million has been provided for CVC construction. We continue to estimate that AOC will need about $25.6 million more in CVC construction funds to complete the entire CVC project. This estimate does not allow for risks and uncertainties and takes into account funding that AOC plans to use from existing appropriations. In addition, as we indicated during the March 15 hearing, AOC preliminarily expects to need about $950,000 in fiscal year 2007 AOC general administration appropriations that Congress has not yet provided to pay for contractual support needed to complete acceptance testing of the facility's fire protection system in time to meet the project's schedule. AOC plans to determine if it can reduce the amount needed for this contractual support; we will keep Congress apprised of this situation.

Nov 24, 2020

Nov 23, 2020

Nov 18, 2020

Nov 16, 2020

Oct 7, 2020

Sep 25, 2020

Sep 23, 2020

Sep 10, 2020

Looking for more? Browse all our products here