This is the accessible text file for GAO report number GAO-06-665T entitled 'Capitol Visitor Center: Update on Status of Project's Schedule and Cost as of April 27, 2006' which was released on April 27, 2006. This text file was formatted by the U.S. Government Accountability Office (GAO) to be accessible to users with visual impairments, as part of a longer term project to improve GAO products' accessibility. Every attempt has been made to maintain the structural and data integrity of the original printed product. Accessibility features, such as text descriptions of tables, consecutively numbered footnotes placed at the end of the file, and the text of agency comment letters, are provided but may not exactly duplicate the presentation or format of the printed version. The portable document format (PDF) file is an exact electronic replica of the printed version. We welcome your feedback. Please E-mail your comments regarding the contents or accessibility features of this document to Webmaster@gao.gov. This is a work of the U.S. government and is not subject to copyright protection in the United States. It may be reproduced and distributed in its entirety without further permission from GAO. Because this work may contain copyrighted images or other material, permission from the copyright holder may be necessary if you wish to reproduce this material separately. United States Government Accountability Office: GAO: Testimony: Before the Subcommittee on the Legislative Branch, Committee on Appropriations, U.S. Senate: Capitol Visitor Center: Update on Status of Project's Schedule and Cost as of April 27, 2006: Statement of Terrell Dorn, Director: Bernard L. Ungar: Director: Physical Infrastructure Issues: GAO-06-665T: Mr. Chairman and Members of the Subcommittee: We are pleased to be here today to assist the Subcommittee in monitoring progress on the Capitol Visitor Center (CVC) project. Our remarks will focus on the Architect of the Capitol's progress in achieving selected project milestones and in managing the project's schedule since the Subcommittee's March 15, 2006, hearing on the project.[Footnote 1] As part of this discussion, we will address a number of key challenges and risks that continue to face the project, as well as actions AOC has taken or plans to take to address these risks. In addition, we will discuss the status of the project's costs and funding. Our remarks today are based on our review of schedules and financial reports for the CVC project and related records maintained by AOC and its construction management contractor, Gilbane Building Company; our observations on the progress of work at the CVC construction site; and our discussions with the CVC team (AOC and its major CVC contractors), AOC's Chief Fire Marshal, and representatives from the U.S. Capitol Police. We also reviewed AOC's construction management contractor's periodic schedule assessments and daily reports on the progress of interior wall and floor stonework. In summary: Since the Subcommittee's March 15 CVC hearing, the CVC team has continued to move the project's construction forward, and AOC is still proposing the same opening dates--April 2007 for the base CVC project and May 2007 for the House and Senate expansion spaces--but we continue to believe, as we said at the March hearing, that the proposed opening dates do not allow enough time to complete several critical activities and to address problems, challenges, risks, and uncertainties. Since the March 15 hearing, the installation of critical interior wall and floor stone has continued, together with other interior and exterior construction work, and the sequence 2 contractor has further developed plans to prevent trade stacking[Footnote 2] during finish work. However, the pace of interior wall and floor stone installation remained below the targeted pace; the dates for completing the construction of the overall base project and expansion spaces were extended; and several activities fell behind schedule--not enough to affect the overall completion dates yet, but increasing the potential for future delays. In addition, the sequence 2 contractor met only 1 of the 13 milestones being tracked for this hearing, and this contractor's monthly billings indicate that construction work is not likely to be completed on schedule as AOC anticipated. The CVC's fire protection system has not yet been approved; critical building systems still have to be commissioned and tested; and although the project's overall design is essentially complete, certain design or work scope elements are still incomplete or are being clarified or refined. If the CVC team is successful in addressing these issues, we believe that the base CVC project can still possibly be opened to the public with a temporary cap on visitor occupancy in May 2007 and that the expansion spaces can likely be opened for occupancy beginning in mid-August to early September 2007. AOC may be able to reduce some of the time scheduled for the expansion spaces if it implements a phased opening plan and is able to perform acceptance testing of the CVC and the expansion spaces concurrently rather than sequentially--possibilities AOC is continuing to explore. However, the delays that have occurred since the Subcommittee's last CVC hearing compound the concern we previously expressed that AOC will be challenged to meet even the later dates we are projecting because of the problems, challenges, risks, and uncertainties facing the project. Accordingly, we plan to reassess the project's schedule again this summer. As we reported at the Subcommittee's March 15 CVC hearing, we estimate that the total cost to complete the entire CVC project is about $556 million without an allowance for risks and uncertainties and $584 million with such an allowance. To date, about $530 million has been provided for CVC construction. We continue to estimate that AOC will need about $25.6 million more in CVC construction funds to complete the entire CVC project. This estimate does not allow for risks and uncertainties and takes into account funding that AOC plans to use from existing appropriations. In addition, as we indicated during the March 15 hearing, AOC preliminarily expects to need about $950,000 in fiscal year 2007 AOC general administration appropriations that Congress has not yet provided to pay for contractual support needed to complete acceptance testing of the facility's fire protection system in time to meet the project's schedule. AOC plans to determine if it can reduce the amount needed for this contractual support; we will keep the Subcommittee apprised of this situation. AOC Has Moved Construction Forward, but Delays Continue and Risks and Uncertainties Remain: AOC and it contractors have made progress in a number of areas since the Subcommittee's last CVC hearing, particularly in installing wall stone in the orientation and security lobby and in the south atrium. However, some milestones were pushed back in March. For example, according to AOC's March 2006 schedule, the base CVC project will have a temporary certificate of occupancy on February 21, 2007, 6 workdays later than indicated in the February 2006 schedule, and the House and Senate expansion spaces will be substantially complete on December 18, 2006, 1 workday later than indicated in the February 2006 schedule. AOC is still proposing an April 2007 opening date for the base project and a May 2007 occupancy date for the expansion spaces--dates that it believes will accommodate possible delays and allow start-up time for operations. AOC expects all construction work in the CVC, East Front, and expansion spaces to be completed by the April opening date for the base project, but the CVC's occupancy at any one time will be temporarily limited to 3,500, compared with about 4,200, the normal anticipated occupancy level.[Footnote 3] Schedule slippages that have occurred since the Subcommittee's March 15 CVC hearing, coupled with the challenges, risks, and uncertainties that continue to face the project, have heightened our concerns about AOC's ability to open the CVC to the public in April 2007. Consequently, we plan to reassess the project's schedule again this summer. Our Analysis Indicates Later Opening Dates Than AOC Is Proposing: We continue to believe, as we testified in March, that the CVC is not likely to be ready for opening with a temporary certificate of occupancy before May 2007, about a month later than AOC is proposing. Our projected opening date is somewhat later than AOC's because certain critical work, such as interior stonework for the base project and East Front, has not generally been proceeding as quickly as planned and CVC team managers and members believe that certain other work, such as finish work, will take more time than is scheduled to complete. Our projection also assumes that AOC will be able to address the challenges it faces and takes into account the time that AOC believes is necessary to prepare for operations after construction work is completed. However, schedule slippages in March raise concerns about AOC's ability to overcome these challenges. Similarly, we continue to believe that the House and Senate expansion spaces are more likely to be ready in mid-August or early September 2007 than in April or May 2007, as AOC is proposing. We consider the later time frames for the expansion spaces more likely for three reasons. First, AOC has scheduled the acceptance testing of the expansion spaces after the acceptance testing of the base project and, according to our analysis, the base project's testing will take longer than scheduled. Second, AOC's Chief Fire Marshal believes the acceptance testing of the expansion spaces will take longer than scheduled. Third, several activities important to the on- time completion of expansion-space work slipped in March; and at this time, the sequence 2 subcontractor responsible for this work believes that additional slippages in some of these activities are likely. However, AOC has begun to address the problems affecting the progress of the expansion spaces and plans to reassess this situation as the construction work proceeds. The expansion spaces could be ready sooner than late summer 2007 if AOC succeeds in addressing the problems and starts acceptance testing sooner or opens the expansion spaces in phases--possibilities that AOC is continuing to explore. Construction Work Is Progressing: According to AOC's construction management contractor, work on the project has advanced, in terms of both the dollar value of the work in place and individual project elements. In dollar terms, the overall CVC project was about 79 percent complete and the sequence 2 work was about 67 percent complete as of March 31-up from about 77 percent and 63 percent, respectively, as of February 28. Additionally, wall stone installation progressed substantially in the orientation and security lobby and in the south atrium and continued in other areas, such as the great hall and the East Front's basement level. AOC's construction management contractor reported additional progress in the CVC's interior, the utility and House connector tunnels, the House and Senate expansion spaces, and the building's exterior, such as on the plaza's east side in preparation for tree planting, which occurred north and south of the auditorium in April. In fact, AOC's construction management contractor reported that the CVC's electrical work was ahead of schedule. Indicators Raise Questions about Proposed Opening Dates: Despite the progress in these areas, problems and delays occurred in other areas, and several indicators of construction progress that we have been tracking for the Subcommittee continue to indicate that construction work is likely to be completed later than AOC currently anticipates. An update on these indicators follows. Sequence 2 contractor continues to miss milestones and completion dates are extended. Starting with the Subcommittee's June 2005 CVC hearing, at the Subcommittee's request, we and AOC have been selecting and tracking sequence 2 milestones to help the Subcommittee monitor construction progress. These milestones include activities that are either on the project's critical path or that we and AOC believe are critical to the project's timely completion. As figure 1 shows, the sequence 2 contractor has generally missed these milestones. For today's hearing, 13 of these milestones were due to be completed, according to the project's January 2006 schedule. One was completed ahead of schedule; 2 were completed late; and none of the remaining 10 had been completed as of April 24. (See app. I.) Figure 1: Sequence 2 Contractor's Progress in Meeting Selected Milestones as of CVC Hearing Dates: [See PDF for image] Source: Sequence 2 contractor, AOC and its construction management contractor, and GAO. [End of figure] According to AOC's construction management contractor, the base project's overall completion date fell 6 workdays behind in March, from February 13 to February 21, 2007. The February 13 date was set in the project's January 2006 schedule. This 6-workday delay is the net result of delays in activities on multiple activity paths. In addition, slippages occurred on 15 of 19 critical and near-critical paths that AOC's construction management contractor identified as important to meeting the base project's overall completion date.[Footnote 4] These delays occurred in, but were not limited to, work on the East Front, the upper level of the orientation and security lobby, the auditorium, the utility tunnel, the assembly room, and the orientation theaters, and they ranged from 1 to more than 80 workdays. According to the CVC team, these project delays occurred for a variety of reasons, such as design changes, problematic sequence 1 work, late submissions or approvals of shop drawings, and changes in the sequence of work activities by the sequence 2 contractor. Even more important than the individual delays themselves, however, is their likely impact on the CVC team's ability to complete construction work on schedule. So many activities have now fallen behind schedule that even relatively short additional delays could push back the CVC's overall completion date. According to the construction management contractor, there are nine critical and near-critical activity paths in the project's March schedule that have so little slack time that an additional delay of 1 to 30 workdays could delay the base project's overall completion date. There were six such paths in the project's February schedule. Work on the House and Senate expansion spaces fell 1 workday behind schedule in March, AOC's construction management contractor reported.[Footnote 5] Additionally, and of even greater concern to us, are delays in a number of near-critical paths. Some of these paths slipped as much as 29 workdays in March. Although most of the time that was lost in March did not affect the overall completion date for the expansion spaces, further delays could do so. Among the activities that were delayed in March were plumbing installation on the House service level; duct work installation in space intended for use by the U.S. Capitol Police; testing and balancing of the heating, ventilation, and air conditioning systems on the Senate upper level; and completion of the fire alarm system in the House lower level. According to the CVC team, these activities were delayed because of problems associated with sequence 1 or other sequence 2 work, delays in getting approved shop drawings, and delays in completing necessary predecessor work or in getting design decisions. In early April 2006, we told AOC we were concerned about the increasing number of delays in expansion space activities and the potential impact of these delays on the completion of the expansion space work. As further cause for concern, we noted that the sequence 2 subcontractor doing the expansion space work was expecting additional delays in some of these activities and that, in our view, additional design or scope changes were possible. Although AOC is not planning to open the expansion spaces until May 2007, timely completion of the expansion space work is important because certain expansion space work must be completed before the CVC can be opened to the public. AOC agreed that continued delays in the expansion space work are of concern and recognized that risks and uncertainties associated with the work could cause the work to fall farther behind. AOC has begun to work with the rest of the CVC team to identify and address problems that have arisen and risks that threaten the work's on-time completion. Value of completed work indicates completion later than scheduled. Another indicator of construction progress that we and AOC's construction management contractor have been tracking is the value of the completed construction work billed to the government each month. Both we and the construction management contractor believe that the sequence 2 contractor's monthly billings, including the bill for March 2006, have generally not been sufficient to meet AOC's currently scheduled completion date. While this indicator has some limitations (for example, billings lag behind construction and the contract's total value does not include the value of modifications that are beyond modification 85), it is generally regarded in the construction industry as a useful measure of how likely a project is to be completed on time. Figure 2 compares the sequence 2 contractor's billings since May 2003 with the project's scheduled completion date and indicates that the sequence 2 contractor is not likely to finish construction work by December 2006, as AOC expects, unless the value of completed work increases significantly. We believe that a significant increase will be difficult, given the limited number of areas that will be ready for finish work at any given time. Figure 2: Total Billings by the Sequence 2 Contractor for the Entire CVC Project Compared with the Billings Needed to Finish Construction Work on Schedule: [See PDF for image] Source: AOC's construction management contractor. Notes: 1. The early and late lines on this figure reflect the cumulative billings that would be required to complete the project through contract modification 85 ($222.8 million total contact value) by the early and late finish dates shown in the sequence 2 contractor's schedule. 2. The actual line reflects the sequence 2 contractor's actual monthly billings. 3. Although bills are typically submitted for payment after work is completed, it is often likely that construction work will be completed on schedule when the actual billing line falls between the early and late lines in the figure. With respect to the CVC, the actual billing line has been trending below, and in March 2006 went below, the late finish line. Even with the lag in billings, this trend indicates that the amount of work being completed each month is not sufficient to finish the project on schedule. [End of figure] Interior stone installation is progressing, but taking longer than expected. Overall, about 64 percent of the CVC's interior wall stone has been installed, according to AOC's construction management contractor, and the sequence 2 contractor installed 5,079 pieces of interior wall stone during the last 5 weeks, meeting about 94 percent of its 5,384-piece production target. By contrast, during the same period, the sequence 2 contractor installed about 3,090 square feet of floor stone, or about one-third of the 9,300 square feet specified in a preliminary floor stone installation plan that the contractor provided to AOC shortly after the February 15 hearing. In addition, 7 of the 13 schedule milestones that AOC and we have been tracking for the Subcommittee for today's hearing are related to interior wall stone installation, and the sequence 2 contractor met 1 of these 7 milestones. According to the CVC team, the sequence 2 contractor has missed its stone installation targets for a variety of reasons, including the need to correct problematic sequence 1 work or properly prepare certain spaces for the installation of wall or floor stone, a change in wall stone design, late delivery of floor stone, or delays in some spaces in finishing certain work, such as ceiling work, that usually precedes floor stone installation. As we have discussed in the Subcommittee's previous CVC hearings, delays in wall stone installation can lead to additional delays in completing follow-on work, such as floor stone installation and finish work. Although the CVC team has identified unforeseen conditions and problematic sequence 1 work as risks that could affect the pace of wall stone installation, the team's efforts to address the risks have not fully prevented these types of problems from recurring or adversely affecting the project's schedule. Figures 3 and 4 show the sequence 2 contractor's progress in installing interior wall and floor stone since January 23 and February 13, 2006, respectively. Figure 3: Progress of CVC Interior Wall Stone Installation Compared with Targets Set by the Sequence 2 Contractor: [See PDF for image] Source: AOC's construction management contractor. [End of figure] Figure 4: Progress of CVC Interior Floor Stone Installation Compared with Preliminary Targets Set by the Sequence 2 Contractor: [See PDF for image] Source: AOC's construction management contractor. [End of figure] Project's Schedule Remains Vulnerable to Problems, Challenges, Risks, and Uncertainties, despite Actions AOC Has Taken and Plans to Take: As we indicated during the Subcommittee's February 15 and March 15 CVC hearings, we continue to believe that AOC will be challenged to meet even the later opening dates we have identified, given the problems, challenges, risks, and uncertainties facing the project. A brief update on these and AOC's plans for addressing them follows: * Trade stacking could delay completion. As we discussed during the Subcommittee's previous CVC hearings, trade stacking could hold up finish work, such as drywall or ceiling installation, electrical and plumbing work, plastering, or floor stone installation. This work could be stacked because of delays in wall stone installation. According to AOC's construction management contractor, the pace of wall stone installation during March has not been sufficient to eliminate the risk of trade stacking and delays in finish work. Such a situation could also increase the risk of accidents and injuries. Hence, it remains important, as we said at the previous CVC hearings, for the CVC team to closely monitor construction to identify potential trade stacking and promptly take steps to address it. The CVC team has also identified trade stacking as a high risk, and since the Subcommittee's March 15 CVC hearing, the sequence 2 contractor has continued to develop area- by-area plans that will show when each subcontractor will be working in each area. The sequence 2 contractor has finished these plans for most of the work areas and expects to have plans for the remaining areas completed by the end of this week. According to the sequence 2 contractor, it has been meeting with its key subcontractors to reach agreement on the plans and intends to continue meeting regularly with them to review and update the plans. The sequence 2 contractor pointed out that these plans add more detail to the project's schedule and will serve as a tool for addressing the trade-stacking issue. Although we and AOC agree that these area-by-area plans are important and should be helpful, we are still concerned about the potential for trade stacking because of the delays that have already occurred and the delays that could occur if shop drawings for the fire protection system are not approved in time to avoid slippages in follow-on work or if changes are required as a result of the Fire Marshal Division's review of the drawings. * Complex building systems remain a significant risk. The CVC will house complex building systems, including systems for heating, air conditioning, and ventilation; fire protection; and security. These systems not only have to perform well individually, but their operation also has to be integrated. If the CVC team encounters any significant problems with their functioning, either individually or together, during commissioning or acceptance testing, the project could be seriously delayed. During the Subcommittee's March 15 CVC hearing, we noted that the sequence 2 contractor planned to submit the shop drawings for the CVC's fire protection system for review by March 17. However, the contractor has not submitted the drawings for the base project as of April 24, in part because more time was needed to incorporate changes, AOC's construction management contractor said. AOC expects the drawings to be submitted by the end of this week. Delays could arise if the proposed system does not meet the project's design specifications or the fire protection code's requirements.[Footnote 6] AOC's Chief Fire Marshal believes that it will take at least 4 weeks to review these drawings. In addition, the Chief Fire Marshal notes that delays could occur if the CVC team does not adequately pretest the system and correct any problems found during the pretesting. Since the Subcommittee's last CVC hearing, AOC's commissioning contractor submitted its plan for testing the performance of the CVC's smoke control system, which is a critical component of the CVC's fire protection system and must work properly before the CVC can be opened to the public. This plan has not yet been approved. In addition, as we have previously noted, the Chief Fire Marshal's timely completion of the fire protection system's acceptance testing depends on his ability to obtain sufficient funding for a contractor to help perform the tests. Furthermore, difficulties the CVC team has had resolving scope, design, and cost issues associated with the CVC's technical security system could adversely affect the schedule for acquiring and installing cabling and equipment for this system, including door hardware. The CVC team and representatives from the U.S. Capitol Police have been working to resolve these problems. Nevertheless, according to AOC's construction management contractor, certain changes to the scope of the security work are likely to set the schedule back to some extent. * Building design and work scope continue to evolve. The CVC has undergone a number of design and work scope changes. Since the project began, AOC's architectural contractor has issued over 180 design changes or clarifications, and as of April 20, 2006, reported having another 14 in process. In addition, since the project began, AOC has executed more than 80 sequence 2 contract modifications valued at over $23 million for work that was not anticipated.[Footnote 7] Some of these changes, such as changes in the exhibit gallery and in the East Front, have resulted in delays. In addition, shop drawings for a number of project elements, such as the facility's fire protection system, millwork in the food service area and assembly rooms, and certain portions of the exhibit gallery, have not yet been fully approved and are subject to change, and additional design or scope changes are likely given the project's experience to date. Project design and scope changes are typically reflected in the development of potential change orders (PCO), many of which result in contract modifications. Figure 5 shows the PCOs submitted for consideration for sequences 1 and 2 since September 2003. Although PCOs are not always approved, they are often regarded as a reasonably good indicator of likely future design or scope changes that can affect a project's cost and schedule. Even more important, the adverse impact of scope and design changes on a project's schedule is likely to increase as the project moves toward completion. For example, certain changes to the fire protection system currently being discussed are likely, if made, to adversely affect the project's schedule, according to AOC. Figure 5: Cumulative Number of Potential Change Orders Submitted for CVC Sequences 1 and 2 between September 2003 and April 2006: [See PDF for image] Source: AOC's construction management contractor. [End of figure] As the figure indicates, new PCOs for sequence 1 were submitted until shortly before, and even for several months after, November 2004, when AOC determined that the sequence 1 contract work was substantially complete. Similarly, PCOs for sequence 2 are still being submitted, and we have seen no indication that their submission is likely to stop soon. While not all PCOs are approved, many are, and it appears likely to us that some of the design or scope changes indicated in PCOs could lead to contract modifications that will affect the project's schedule. AOC agrees that it is important to minimize the impact of proposed design and scope changes. * Opening the CVC and expansion spaces at different times is likely to result in a temporary cap on CVC occupancy and increase costs. As we reported during the Subcommittee's February 15 and March 15 CVC hearings, AOC's current plan to open the CVC in April 2007 before the expansion spaces are scheduled for completion is likely to result in a temporary cap on CVC visitor occupancy and a need to construct temporary emergency exits for fire and life safety protection.[Footnote 8] AOC is proposing this sequential approach because it believes that conducting acceptance testing for the fire protection system for the CVC and the expansion spaces concurrently would delay opening the CVC to the public. AOC's proposed April 2007 opening date for the CVC depends on the timely completion of work not only on the base project but also on the expansion spaces, since certain expansion space work must be completed before the CVC's opening. Inasmuch as work on both the base project and the expansion spaces was delayed in March, we believe that it will be especially important to monitor the progress of construction to determine what additional work (and funding) may be needed to meet AOC's planned date for opening the CVC, including what temporary work may be required in the expansion spaces for the CVC to open before the expansion space work is complete. According to AOC, it plans to have its construction management contractor monitor this situation. * Risks from insufficient stone deliveries remain, but may be diminishing. According to the sequence 2 contractor, it has, since the Subcommittee's last CVC hearing, received 12 of the 12.5 truckloads of interior wall stone it was expecting from the stone fabricator and expects to receive the remaining wall stone needed for the base project by mid-June 2006. AOC's construction management contractor reported that as of last week, almost all--about 98 percent--of the wall stone needed for the core CVC itself was on site (either installed or awaiting installation); about 44 percent of the wall stone needed for the atriums and about 30 percent of the wall stone needed for the East Front were on site; and none of the wall stone for the House connector, Library of Congress, and Cannon tunnels had been delivered. According to AOC and its construction management contractor, although the supply of interior wall stone was insufficient in late 2005 and early 2006, it is adequate for the CVC at this time, given the amount of space available for wall stone installation and the quantity of stone on hand--over 6,800 pieces. Furthermore, they said that they do not expect the wall stone supply for the base project to cause further delays in the CVC's opening, provided that the fabricator sustains the pace of deliveries, particularly for the East Front, whose completion is critical to the CVC's opening. Also, although none of the wall stone for the House and Senate expansion spaces was on site yet, the subcontractor responsible for this work is not anticipating delivery problems at this time. On the other hand, AOC's construction management contractor reported that no floor stone was installed during the week of April 10 because, as a result of a late delivery from the supplier, the installers ran out of floor stone for the exhibit gallery. The sequence 2 contractor said this late delivery was unusual for floor stone and no further problems with floor stone supply were expected. Finally, as we have said in previous discussions with AOC, its construction management contractor, and the Subcommittee, it will be important for AOC to have adequate analysis and documentation of the reasons and responsibilities for delays.[Footnote 9] On April 11, 2006, AOC executed a contract modification authorizing its construction management contractor to have one of its managers who has not been involved in the CVC project assess the adequacy of this type of information. AOC expects this assessment to be completed soon. Estimated Project Cost and Funding: As we testified during the Subcommittee's March 15 CVC hearing, we estimate that the total cost to complete the entire CVC project will be about $556 million without an allowance for risks and uncertainties and could be as much as about $584 million with such an allowance. To date, about $530 million has been provided for CVC construction. This amount includes about $3.6 million that was made available for either CVC construction or operations and has been approved for CVC construction by the House and Senate Committees on Appropriations.[Footnote 10] To obtain the additional funding that it expected to need to complete the project's construction, AOC, in December 2005, requested $20.6 million as part of its budget request for fiscal year 2007. This request was based, in part, on discussions with us and took into account our November 16, 2005, estimate of the cost to complete the project's construction without an allowance for risks and uncertainties and funding from existing appropriations. Our subsequent work--completed in preparation for the Subcommittee's February 15 and March 15 CVC hearings--indicated that AOC would need about $5 million more, or about $25.6 million in additional CVC construction funds, to complete construction without an allowance for risks and uncertainties. AOC plans to request the additional $5 million as a supplement to its fiscal year 2007 budget for CVC construction. This would bring its total request for fiscal year 2007 CVC construction funds to $25.6 million. In addition, AOC has indicated that it plans to use about $950,000 of the fiscal year 2007 general administration appropriations it has requested for contractual support for its Fire Marshal Division. As we stated in our March 15 testimony, AOC believes that it may be able to reduce the amount of funds it will need in fiscal year 2007 for contractual support in testing the CVC's fire protection system and plans to explore ways to do so. AOC expects that its Fire Marshal Division should receive the shop drawings for the CVC's fire protection system by the first week in May, and the Chief Fire Marshal believes that his office will need at least 4 weeks to complete its review. It then plans to determine how much contractual support it will need to test the system and to explore cost savings possibilities. We plan to monitor and report on these costs to the Subcommittee as soon as AOC has a firmer estimate. Also, at this time, it appears that sufficient contingency funding may be available within the current CVC budget to cover the cost increases associated with the security system issues we previously discussed. We will keep the Subcommittee apprised of this situation. Mr. Chairman, this completes our prepared statement. We would be pleased to answer any questions that you or Members of the Subcommittee may have. Contacts and Acknowledgments: For further information about this testimony, please contact Bernard Ungar at (202) 512-4232 or Terrell Dorn at (202) 512-6923. Other key contributors to this testimony include Shirley Abel, John Craig, Maria Edelstein, Elizabeth Eisenstadt, Brett Fallavollita, Jeanette Franzel, Jackie Hamilton, Bradley James, Joshua Ormond, Scott Riback, and Regina Santucci. [End of section] Appendix I: Capitol Visitor Center Critical Construction Milestones, March 16-April 27, 2006: Table 1: Activity: Frame Plaster Ceiling; Location: Great Hall; Scheduled completion: 3/17/06; Actual completion: 4/14/06. Activity: Wall Stone Area 3; Location: East Front Basement; Scheduled completion: 3/20/06; Actual completion: [Empty]. Activity: Wall Stone Area 5; Location: Auditorium; Scheduled completion: 3/22/06; Actual completion: 4/18/06. Activity: Wall Stone Area 2; Location: Orientation Lobby Upper Level; Scheduled completion: 3/27/06; Actual completion: [Empty]. Activity: Wall Stone Area 3; Location: Orientation Lobby Upper Level; Scheduled completion: 3/31/06; Actual completion: 3/09/06. Activity: Lath Plaster Ceiling; Location: Great Hall; Scheduled completion: 3/31/06; Actual completion: [Empty]. Activity: Wall Stone Area 1; Location: East Front Ground; Scheduled completion: 4/03/06; Actual completion: [Empty]. Activity: Grid for Wood Ceiling; Location: Orientation Theater; Scheduled completion: 4/03/06; Actual completion: [Empty]. Activity: Plaster Ceilings; Location: Great Hall; Scheduled completion: 4/06/06; Actual completion: [Empty]. Activity: Wall Stone Area 2; Location: East Front Ground; Scheduled completion: 4/17/06; Actual completion: [Empty]. Activity: Install Bronze Doors; Location: Food Service; Scheduled completion: 4/17/06; Actual completion: [Empty]. Activity: Install Wood Ceiling Panels; Location: Orientation Theater; Scheduled completion: 4/17/06; Actual completion: [Empty]. Activity: Wall Stone Area 4; Location: Orientation Lobby; Scheduled completion: 4/21/06; Actual completion: [Empty]. Source: AOC's January 2006 CVC sequence 2 construction schedule for the scheduled early completion dates and AOC and its construction management contractor for the actual completion dates as of April 24, 2006. [End of table] [End of Section] GAO's Mission: The Government Accountability Office, the audit, evaluation and investigative arm of Congress, exists to support Congress in meeting its constitutional responsibilities and to help improve the performance and accountability of the federal government for the American people. GAO examines the use of public funds; evaluates federal programs and policies; and provides analyses, recommendations, and other assistance to help Congress make informed oversight, policy, and funding decisions. GAO's commitment to good government is reflected in its core values of accountability, integrity, and reliability. Obtaining Copies of GAO Reports and Testimony: The fastest and easiest way to obtain copies of GAO documents at no cost is through GAO's Web site (www.gao.gov). Each weekday, GAO posts newly released reports, testimony, and correspondence on its Web site. To have GAO e-mail you a list of newly posted products every afternoon, go to www.gao.gov and select "Subscribe to Updates." Order by Mail or Phone: The first copy of each printed report is free. Additional copies are $2 each. A check or money order should be made out to the Superintendent of Documents. GAO also accepts VISA and Mastercard. Orders for 100 or more copies mailed to a single address are discounted 25 percent. Orders should be sent to: U.S. Government Accountability Office 441 G Street NW, Room LM Washington, D.C. 20548: To order by Phone: Voice: (202) 512-6000 TDD: (202) 512-2537 Fax: (202) 512-6061: To Report Fraud, Waste, and Abuse in Federal Programs: Contact: Web site: www.gao.gov/fraudnet/fraudnet.htm E-mail: fraudnet@gao.gov Automated answering system: (800) 424-5454 or (202) 512-7470: Congressional Relations: Gloria Jarmon, Managing Director, JarmonG@gao.gov (202) 512-4400 U.S. Government Accountability Office, 441 G Street NW, Room 7125 Washington, D.C. 20548: Public Affairs: Paul Anderson, Managing Director, AndersonP1@gao.gov (202) 512-4800 U.S. Government Accountability Office, 441 G Street NW, Room 7149 Washington, D.C. 20548: FOOTNOTES [1] GAO, Capitol Visitor Center: Status of Project's Schedule and Cost as of March 15, 2006, GA0-06-528T (Washington, D.C.: Mar. 15, 2006). [2] Trade stacking can occur when workers from different trades, such as stone masons, electricians, plumbers, or plasterers, have to work in the same area at the same time to meet a schedule, sometimes making it difficult to ensure sufficient space and resources for concurrent work. [3] This temporary limit will be necessary because the "horizontal exits," or passages, through the expansion spaces, which the life safety code requires for exiting the base CVC project, will not be available until later. These horizontal exits cannot be used until the fire alarm system in the expansion spaces has been fully tested and accepted--work that is not slated to be completed until after the base CVC is scheduled to open. Some additional work will likely be required to provide temporary emergency exit routes from the CVC, but the CVC team does not believe that this work or its costs should be substantial. [4] Construction projects typically have one critical path, which is the sequence of activities having the longest duration through the schedule. There is no slack time associated with these activities, meaning that a delay in a critical path activity will delay the entire project unless a way is found to reduce the time required for other activities along the critical path. Some projects have multiple critical paths simultaneously; the CVC essentially has two concurrent critical paths--(1) East Front mechanical and (2) East Front fire acceptance testing--and many near critical activity paths which have little slack time. Generally, the more critical and near-critical activities a project has, the greater is the risk of late completion because there are more opportunities for slight delays that can adversely affect the project's completion. [5] According to the project's February and March schedules, the overall completion of the House and Senate expansion spaces remained the same--May 2, 2007. The contract completion date for this work is March 12, 2007. [6] According to the sequence 2 subcontractor that is fitting out the House and Senate expansion spaces, the delays in getting approved shop drawings for the fire protection system have already postponed ceiling close ins in the expansion spaces, and the subcontractor's CVC project director believes that further such delays pose the single greatest risk to the completion schedule for the expansion spaces at this time. [7] These data exclude sequence 2 contract modifications for work that was planned but not included in the sequence 2 base contract. Examples include the fit-out of the House and Senate shell spaces, the construction of the utility tunnel, and the purchase and installation of food service equipment. [8] According to AOC, the CVC's occupancy at any one time would be temporarily limited to 3,500, compared with about 4,200, the normal anticipated occupancy level, until acceptance testing of the fire protection system for the expansion spaces has been completed. [9] See for example: GAO, Capitol Visitor Center: Effective Schedule Management and Updated Cost Information Are Important, GAO-05-811T (Washington, D.C.: June 14, 2005). [10] Public Law 108-447, enacted on December 8, 2004, provided that up to $10.6 million could be transferred from AOC's Capitol Building appropriation account for the use of the CVC project. The use of the amount transferred is subject to the approval of the House and Senate Committees on Appropriations. In June 2005, AOC received approval to use about $2.8 million (including about $1.6 million for CVC construction) of this $10.6 million, leaving a balance of about $7.7 million that could be used in the future after a rescission amounting to $84,800. AOC recently received approval to use about an additional $2 million of these funds for CVC construction, including, for example, the fabrication and installation of wayfinding signage and the fit-out of the gift shops, and about $2.3 million for CVC operations. Thus, about $3.4 million of the $10.6 million remains available for approval for use for CVC construction or operations.