Appeal of -- The Clark Construction Group, Inc. Under Contract No. AOC-9800017

2003-1: Nov 23, 2004

Additional Materials:


Contract Appeals Board
(202) 512-3342


Office of Public Affairs
(202) 512-4800

The Clark Construction Group, Inc. (Clark or Appellant) appeals the decision of the Architect of the Capitol (AOC, Government or Respondent) denying its claims and seeks $12,406,250 in damages arising out of alleged delay, acceleration and changes to its contract No. 9800017 for the renovation of the United States Botanic Garden Conservatory. This Board's jurisdiction of this appeal is pursuant to the Disputes Clause in the contract and the appointment of the Board by the Joint Committee on the Library by letter dated December 13, 2002. A hearing was held on both entitlement and quantum pursuant to the rules established by the Board.

We sustain the appeal, in part.

Mar 27, 2020

Mar 26, 2020

Mar 25, 2020

Mar 24, 2020

Mar 19, 2020

Looking for more? Browse all our products here