Appeal of -- The Clark Construction Group, Inc. Under Contract No. AOC-9800017
2003-1: Nov 23, 2004
The Clark Construction Group, Inc. (Clark or Appellant) appeals the decision of the Architect of the Capitol (AOC, Government or Respondent) denying its claims and seeks $12,406,250 in damages arising out of alleged delay, acceleration and changes to its contract No. 9800017 for the renovation of the United States Botanic Garden Conservatory. This Board's jurisdiction of this appeal is pursuant to the Disputes Clause in the contract and the appointment of the Board by the Joint Committee on the Library by letter dated December 13, 2002. A hearing was held on both entitlement and quantum pursuant to the rules established by the Board.
We sustain the appeal, in part.